化工建設(shè)工程設(shè)計合同范本3篇
化工建設(shè)工程設(shè)計合同范本3篇
化工基本建設(shè)是指化工企業(yè)或部門在化工設(shè)計的基礎(chǔ)上,以擴大再生產(chǎn)、提高技術(shù)水平、調(diào)整產(chǎn)品結(jié)構(gòu)、改善地區(qū)布局為目的,而進行新的整體性固定資產(chǎn)投資的經(jīng)濟活動。基本建設(shè)通常在國家計劃的統(tǒng)籌安排下進行的。以下是學習啦小編為大家精心準備的:化工建設(shè)工程設(shè)計合同范本3篇,歡迎參考閱讀!
化工建設(shè)工程設(shè)計合同范本一
工程名稱:
工程地點:
設(shè)計階段:方案設(shè)計階段、施工圖設(shè)計階段、施工階段的配合
甲方:
建筑工程設(shè)計合同乙方:
簽訂日期: 年 月 日
甲方:
乙方:
經(jīng)方案比選甲方委托乙方承擔 夜景亮化設(shè)計 ,經(jīng)雙方協(xié)商一致,
簽訂本合同。
第一條 本合同依據(jù)下列文件簽訂:
1.1《中華人民共和國合同法》《建筑工程勘察設(shè)計合同管理方法》。
1.2國家及地方有關(guān)建設(shè)工程勘察管理法規(guī)和規(guī)章。
1.3建設(shè)工程批準文件。
1.4 甲方提供并經(jīng)雙方認可的資料。
第二條 本合同設(shè)計項目范圍及內(nèi)容: 夜景亮化設(shè)計
第三條 本合同設(shè)計項目工作階段及成果
乙方按照本工程的工程進度分三個階段進行
第一階段:方案設(shè)計階段
2.1考察現(xiàn)有道路環(huán)境條件,包括地面條件、邊界以及道路內(nèi)外的視覺效果。
2.2 收集及整理有關(guān)圖片及其它相關(guān)資料,設(shè)計階段與甲方相互協(xié)調(diào)及開會討論目前所有的圖紙和資料,使之與設(shè)計主旨一致。
2.3方案設(shè)計階段的工作成果如下:
(1)反映總體設(shè)計的效果圖;
(2)說明設(shè)計構(gòu)思的有關(guān)分析圖、設(shè)計效果圖;
(3)表達主要設(shè)計構(gòu)思及設(shè)計特色的方案一份。
第二階段:施工圖設(shè)計階段
2.4提供詳細的施工設(shè)計圖紙。
2.5協(xié)助甲方編制工程進度安排。
2.6制備及編制材料表有關(guān)的工程規(guī)范。協(xié)助甲方審理工程量清單,以便于甲方制訂招標及合約文件。
2.7與甲方一起,為投標單位提供招標答疑。
2.8出席有關(guān)的工程協(xié)調(diào)會議。
2.9其他;
第三階段:施工階段的配合
2.10乙方在施工圖完成后,需與甲方代表、工程承包商一同出席設(shè)計交底會議。
2.11協(xié)助甲方招標、定標,審核廠家提供的照明設(shè)備是否符合設(shè)計要求。在工程定標以后,施工前根據(jù)設(shè)計要求確認物料品種規(guī)格及質(zhì)量;
2.12在施工前及施工期間應根據(jù)現(xiàn)場需要前往工地現(xiàn)場監(jiān)督,以確保所有工程按圖施工,制備初步驗收接受建議書,其上注明需待修改更正的項目;
2.13在施工前及施工期間應根據(jù)現(xiàn)場需要前往工地現(xiàn)場監(jiān)督,以確保所有工程按圖施工,最后的工程驗收;
2.14甲方或施工方在工程過程中要改動設(shè)計或物料,必須先書面通知乙方;
2.15對甲方解決工程施工中出現(xiàn)的技術(shù)性問題,乙方必須予以及時的技術(shù)支持,在保證工程質(zhì)量及設(shè)計效果的前提下提出解決方案。
3、設(shè)計費用支付安排
雙方本著友好協(xié)商原則確定設(shè)計費為人民幣(大寫): ,(如甲方需
提供設(shè)計燈型樣品,樣品費用另行計算);
3.1設(shè)計費結(jié)算與支付方式:
本合同設(shè)計費用按照以下二個階段支付:
合同簽訂后支付設(shè)計費總額的30%,設(shè)計圖紙交付后支付設(shè)計費總額的30%,施工圖交付后支付設(shè)計費總額的30%,照明工程竣工驗收后十五日內(nèi)一次性支付剩余設(shè)計費。
第四條 雙方責任
4.1 甲方責任
4.1.1 甲方按本合同第三規(guī)定的內(nèi)容,在規(guī)定的時間內(nèi)向乙方提交資料及文件,并對其完整性、正確性及時限負責,甲方不得要求乙方違反國家有關(guān)標準進行設(shè)計。
4.1.2 甲方應保護乙方的投標書、設(shè)計方案、文件、資料圖紙、數(shù)據(jù)、計算軟件和專利技術(shù)。未經(jīng)乙方同意,甲方對乙方交付的設(shè)計資料及文件不得擅自修改、復制或向第三
人轉(zhuǎn)讓或用與本合同外的項目,如發(fā)生以上情況,甲方應付法律責任,乙方有權(quán)向甲方提出索賠。
4.2 乙方責任
4.2.1 乙方應按國家技術(shù)規(guī)范、標準、規(guī)程及甲方提出的設(shè)計要求,進行工程設(shè)計,按合同規(guī)定的進度要求提交質(zhì)量合格的設(shè)計資料。并對設(shè)計圖紙的安全性負責。若因為設(shè)計缺陷造成甲方或第三方的傷害及損失,乙方有相應的賠償義務。
4.2.2 乙方采用的主要技術(shù)標準是:
(1) 國家和地方的現(xiàn)行政策、法規(guī)、技術(shù)規(guī)程和規(guī)范。
4.2.3 設(shè)計合理使用年限為 10 年。
4.2.4 乙方按本合同第二條和第四條規(guī)定的內(nèi)容、進度及份數(shù)向甲方交付資料及文件。
4.2.5 乙方交付設(shè)計資料及文件后,按規(guī)定參加有關(guān)的設(shè)計審查,并根據(jù)審查結(jié)論負責對不超出原定范圍的內(nèi)容做必要調(diào)整補充。乙方按合同規(guī)定時限交付設(shè)計資料及文件,本年內(nèi)項目開始施工,負責向甲方及施工單位進行設(shè)計交底、處理有關(guān)設(shè)計問題和參加竣工驗收。在一年內(nèi)項目尚未開始施工,乙方仍負責上述工作,但應按所需工作量向甲方適當收取咨詢服務費,收費額由雙方商定。
第五條 違約責任
5.1 乙方對設(shè)計資料及文件出現(xiàn)的遺漏和錯誤負責修改或補充。由于乙方員錯誤造成工程質(zhì)量事故損失,乙方除負責采取補救措施外,應免收直接受損失部分的設(shè)計費。損失嚴重的根據(jù)損失的程度乙方責任大小向甲方支付賠償金。賠償金由雙方商定,最高額為全額設(shè)計費。
5.2 由于乙方自身原因,延誤了按本合同第四條規(guī)定的設(shè)計資料及設(shè)計文件的交付,應減收該項目應收設(shè)計費的千分之二。
第六條 其他
6.1 本工程設(shè)計資料及文件中,應當注明其規(guī)格、型號、性能等技術(shù)指標,乙方不得指定生產(chǎn)廠、供應商、甲方需要乙方的乙方員配合加工定貨時,所需要費用由甲方承擔。
6.2 由于不可抗力因素致使合同無法履行時,雙方應及時協(xié)商解決。
6.3 本合同發(fā)生爭議,雙方當事人應及時協(xié)商解決,協(xié)商不成的按下列兩種方式解決:
(一)提交工程所在地仲裁委員會仲裁;
(二)依法向工程所在地人民法院起訴。
6.4 本合同一式 4 份,甲方 2 份,乙方 2 份。
6.5 本合同經(jīng)雙方簽章后生效。
6.6雙方履行完合同規(guī)定的義務后,本合同即行終止。
6.7 本合同未盡事宜,雙方可簽訂補充協(xié)議,有關(guān)協(xié)議及雙方認可的來往電報、傳真、會議紀要等,均為本合同組成部分,與本合同具有同等法律效力。
甲方名稱: 乙方名稱:
法定代表人:(簽字) 法定代表人:(簽字)
委托代理人: 委托代理人:
化工建設(shè)工程設(shè)計合同范本二
工程名稱:______________________________
工程地點:_______________________________
合同編號:______________________________
(由設(shè)計人編填)
設(shè)計證書等級:__________________________
發(fā)包人:________________________________
設(shè)計人:________________________________
簽訂日期:______________________________
建設(shè)工程設(shè)計合同中華人民共和國
建設(shè)部
國家工商行政管
理局
發(fā)包人:
____________________________________________________________________________________
設(shè)計人:
____________________________________________________________________________________
發(fā)包人委托設(shè)計人承擔
_______________________________________________________工程設(shè)計,工程地點為____________________________________________,經(jīng)雙方協(xié)商一致,簽訂本合同,共同執(zhí)行。
第一條 本合同簽訂論據(jù)
1.1《中華人民共和國合同法》、《中華人民共和國建筑法》和《建設(shè)工程勘察設(shè)計市場管理規(guī)定》。
1 監(jiān)制
1.2國家及地方有關(guān)建設(shè)工程勘察設(shè)計管理法規(guī)和規(guī)章。
1.3建設(shè)工程批準文件。
第二條 設(shè)計依據(jù)
2.1發(fā)包人給設(shè)計人的委托書或設(shè)計中標文件
2.2發(fā)包人提交的基礎(chǔ)資料
2.3設(shè)計人采用的主要技術(shù)標準是:
_________________________________________________________
______________________________________________________________________________ ______________________________________________________________________________
第三條 合同文件的優(yōu)先次序
構(gòu)成本合同的文件可視為是能互相說明的,如果合同文件存在歧義或不一致,則根據(jù)如下優(yōu)先次序來判斷:
3.1合同書
3.2中標函(文件)
3.3發(fā)包人要求及委托書
3.4投標書
第四條 本合同項目的名稱、規(guī)模、階段、投資及設(shè)計內(nèi)容(根據(jù)行業(yè)特點填寫) ______________________________________________________________________________________________________________________________________________________________________________________
第五條 發(fā)包人向設(shè)計人提交的有關(guān)資料、文件及時間
第六條 設(shè)計人向發(fā)包人交付的設(shè)計文件、份數(shù)、地點及時間
第七條 費用
7.1雙方商定,本合同的設(shè)計費為__________________萬元。收費依據(jù)和計算方法按國家和地方有關(guān)規(guī)定執(zhí)行,國家和地方?jīng)]有規(guī)定的,由雙方商定。
7.2如果上述費用為估算設(shè)計費,則雙方在初步設(shè)計審批后,按批準的初步設(shè)計概算核算設(shè)計費。工程建設(shè)期間如遇概算調(diào)整,則設(shè)計費也應做相應調(diào)整。
第八條 支付方式
8.1本合同生效后三天內(nèi),發(fā)包人支付設(shè)計費總額的20%,計_______________萬元作為定金(合同結(jié)算時,定金抵作設(shè)計費)。
8.2設(shè)計人提交_______________設(shè)計文件后三天內(nèi),發(fā)包人支付設(shè)計費總額的30%,計________________萬元;之后,發(fā)包人應按設(shè)計人所完成的施工圖工作量比例,分期分批向設(shè)計人支付總設(shè)計費的50%,計_______________萬元,施工圖完成后,發(fā)包人結(jié)清設(shè)計費,不留尾款。
8.3雙方委托銀行代付代收有關(guān)費用。
第九條 雙方責任
9.1發(fā)包人責任
9.1.1發(fā)包人按本合同第五條規(guī)定的內(nèi)容,在規(guī)定的時間內(nèi)向設(shè)計人提交基礎(chǔ)資料及文件,并對其完整性、正確性及時限負責。發(fā)包人不得要求設(shè)計人違反國家有關(guān)標準進行設(shè)計。
發(fā)包人提交上述資料及文件超過規(guī)定期限15天以內(nèi),設(shè)計人按本合同第六條規(guī)定的交付設(shè)計文件時間順延;發(fā)包人交付上述資料及文件超過規(guī)定期限15天以上時,設(shè)計人有權(quán)重新確定提交設(shè)計文件的時間。
9.1.2發(fā)包人變更委托設(shè)計項目、規(guī)模、條件或因提交的資料錯誤,或所提交資料作較大修改,以致造成設(shè)計人設(shè)計返工時,雙方除另行協(xié)商簽訂補充協(xié)議(或另訂合同)、重新明確有關(guān)條款外,發(fā)包人應按設(shè)計人所耗工作量向設(shè)計人支付返工費。
在未簽訂合同前發(fā)包人已同意,設(shè)計人為發(fā)包人所做的各項設(shè)計工作,發(fā)包人應支付相應設(shè)計費。
9.1.3在合同履行期間,發(fā)包人要求終止或解除合同,設(shè)計人未開始設(shè)計工作的,不退還發(fā)包人已付的定金;已開始設(shè)計工作的,發(fā)包人應根據(jù)設(shè)計人已進行的實際工作量,不足一半時,按該階段設(shè)計費的一半支付;超過一半時,按該階段設(shè)計費的全部支付。
9.1.4發(fā)包人必須按合同規(guī)定支付定金,收到定金作為設(shè)計人設(shè)計開工的標志。未收到定金,設(shè)計人有權(quán)推遲設(shè)計工作的開工時問,且交付文件的時間順延。
9.1.5發(fā)包人應按本合同規(guī)定的金額和日期向設(shè)計人支付設(shè)計費,每逾期支付一天,應承擔應支付金額千分之二的逾期違約金,且設(shè)計人提交設(shè)計文件的時間順延。逾期超過30天以上時,設(shè)計人有權(quán)暫停履行下階段工作,并書面通知發(fā)包人。發(fā)包人的上級或設(shè)計審批部門對設(shè)計文件不審批或本合同項目停緩建,發(fā)包人均應支付應付的設(shè)計費。
9.1.6發(fā)包人要求設(shè)計人比合同規(guī)定時間提前交付設(shè)計文件時,須征得設(shè)計人同意,不得嚴重背離合理設(shè)計周期,且發(fā)包人應支付趕工費。
9.1.7發(fā)包人應為設(shè)計人派駐現(xiàn)場的工作人員提供工作、生活及交通等方面的便利條件及必要的勞動保護裝備。
9.1.8設(shè)計文件中選用的國家標準圖、部標準圖及地方標準圖由發(fā)包人負責解決。
9.1.9承擔本項目外國專家來設(shè)計人辦公室工作的接待費(包括傳真、電話、復印、辦公等費用)。
9.2設(shè)計人責任
9.2.1設(shè)計人應按國家規(guī)定和合同約定的技術(shù)規(guī)范、標準進行設(shè)計,按本合同第六條規(guī)定的內(nèi)容、時間及份數(shù)向發(fā)包人交付設(shè)計文件(出現(xiàn)9.1.1、9.1.2、9.1.4、9.1.5規(guī)定有關(guān)交付設(shè)計文件順延的情況除外)。并對提交的設(shè)計文件的質(zhì)量負責。
9.2.2設(shè)計合理使用年限為_______________年。
9.2.3負責對外商的設(shè)計資料進行審查,負責該合同項日的設(shè)計聯(lián)絡(luò)工作。
9.2.4設(shè)計人對設(shè)計文件出現(xiàn)的遺漏或錯誤負責修改或補充。由于設(shè)計人設(shè)計錯誤造成工程質(zhì)量事故損失,設(shè)計人除負責采取補救措施外,應免收受損失部分的設(shè)計費,并根據(jù)損失程度向發(fā)包人支付賠償金,賠償金數(shù)額由雙方商定為買際損失的 %。
9.2.5由于設(shè)計人原因,延誤了設(shè)計文件交付時間,每延誤一天,應減收該項目應收設(shè)計費的千分之二。
9.2.6合同生效后,設(shè)計人要求終止或解除合同,設(shè)計人應雙倍返還發(fā)包人已支付的定金。
9.2.7設(shè)計人交付設(shè)計文件后,按規(guī)定參加有關(guān)上級的設(shè)計審查,并根據(jù)審查結(jié)論負責不超出原定范圍的內(nèi)容做必要調(diào)整補充。設(shè)計人按合同規(guī)定時限交付設(shè)計文件一年內(nèi)項目開始施工,負責向發(fā)包人及施工單位進行設(shè)計交底、處理有關(guān)設(shè)計問題和參加竣工驗收。在一年內(nèi)項目尚未開始施工,設(shè)計人仍負責上述工作,可按所需工作量向發(fā)包人適當收取咨詢服務費,收費額由雙方商定。
第十條 保密
雙方均應保護對方的知識產(chǎn)權(quán),未經(jīng)對方同意,任何一方均不得對對方的資料及文件擅自修改、復制或向第三人轉(zhuǎn)讓或用于本合同項目外的項目。如發(fā)生以上情況,泄密方承擔一切由此引起的后果并承擔賠償責任。
第十一條 仲裁
本建設(shè)工程設(shè)計合同發(fā)生爭議,發(fā)包人與設(shè)計人應及時協(xié)商解決。也可由當?shù)亟ㄔO(shè)行政主管部門調(diào)解,調(diào)解不成時,雙方當事人同意由_________________________________仲裁委員會仲裁。雙方當事人未在合同中約定仲裁機構(gòu),當事人又未達成仲裁書面協(xié)議的,可向人民法院起訴。
第十二條 合同生效及其他
12.1發(fā)包人要求設(shè)計人派專人長期駐施工現(xiàn)場進行配合與解決有關(guān)問題時,雙方應另行簽訂技術(shù)咨詢服務合同。
12.2設(shè)計人為本合同項目的服務至施工安裝結(jié)束為止。
12.3本工程項目中,設(shè)計人不得指定建筑材料、設(shè)備的生產(chǎn)廠或供貨商。發(fā)包人需要設(shè)計人配合建筑材料。設(shè)備的加工訂貨時,所需費用由發(fā)包人承擔。
12.4發(fā)包人委托設(shè)計人配合引進項目的設(shè)計任務,從詢價、對外談判、國內(nèi)外技術(shù)考察直至建成投產(chǎn)的各個階段,應吸收承擔有關(guān)設(shè)計任務的設(shè)計人員參加。出國費用,除制裝費外,其他費用由發(fā)包人支付。
12.5發(fā)包人委托設(shè)計人承擔本合同內(nèi)容以外的工作服務,另行簽訂協(xié)議并支付費用。 12.6由于不可抗力因素致使合同無法履行時,雙方應及時協(xié)商解決。
12.7本合同雙方簽字蓋章即生效,一式___________份,發(fā)包人__________份,設(shè)計人___________份。
12.8本合同生效后,按規(guī)定應到項目所在地省級建設(shè)行政主管部門規(guī)定的審查部門備案;雙方認為必要時,到工商行政管理部門鑒證。雙方履行完合同規(guī)定的義務后,本合同即行終止。
12.9雙方認可的來往傳真、電報、會議紀要等,均為合同的組成部分,與本合同具有同等法律效力。
12.10未盡事宜,經(jīng)雙方協(xié)商一致,簽訂補充協(xié)議,補充協(xié)議與本合同具有同等效力。 發(fā)包人名稱: 設(shè)計人名稱:
(蓋章) (蓋章)
法定代表人:(簽字) 法定代表人:(簽字)
委托代理人:(簽字) 委托代理人:(簽字)
項目經(jīng)理:(簽字) 項目經(jīng)理:(簽字)
住 所: 住 所:
郵政編碼: 郵政編碼:
電 話: 電 話:
傳 真: 傳 真:
開戶銀行: 開戶銀行:
銀行帳號: 銀行帳號:
建設(shè)行政主管部門備案: 鑒證意見:
(蓋章) (蓋章)
備案號: 經(jīng)辦人:
備案日期: 年 月 日 鑒證日期: 年 月 日
化工建設(shè)工程設(shè)計合同范本三
Design Contract for Construction Project (II)
(專業(yè)建設(shè)工程設(shè)計合同)
(Design Contract for Professional Construction Project)
工 程 名 稱: 10KV變電所新建工程
Project Name:10KV Substation New Construction
工 程 地 點:
Project Site:
合 同 編號:Contract No.:
(由設(shè)計人編填) (Filled in by Designer)
設(shè)計證書等級: 設(shè)證甲級A121001826
Design Certification Rank: Design Certificate Class A 121001826
發(fā) 包 人:Employer:
設(shè) 計 人: 電力勘察設(shè)計院
Designer: Electric Power Survey Design Institute
簽 訂 日 期:Date:
中華人民共和國建設(shè)部國家工商行政管理局
Supervised and Manufactured byMinistry of Construction of People’s Republic of
China and the State Administration of Industry and Commerce
發(fā)包人:Employer:
設(shè)計人:電力勘察設(shè)計院 Designer: Electric Power Survey Design Institute
發(fā)包人委托設(shè)計人承擔 10KV變電所新建工程設(shè)計,工程地點為 ,經(jīng)雙方協(xié)商一致,簽訂本合同,共同執(zhí)行。
The Employer entrusts the Designer to undertake 10KV Star Mall Plaza 1 # Substation New Construction; the project site is No.6, Bei’Er Zhong Road, Tiexi District, Shenyang City. Upon agreement by both parties through consultation, the two parties shall sign and implement the Contract jointly.
第一條 本合同簽訂依據(jù) Article 1: This Contract is signed in accordance with:
1.1《中華人民共和國合同法》、《中華人民共和國建筑法》和《建設(shè)工程勘察設(shè)計市場管理規(guī)定》。
1.1 Contract Law of the People’s Republic of China, Construction Law of the People's Republic of China and Market regulations of Construction Survey and Design.
1.2國家及地方有關(guān)建設(shè)工程勘察設(shè)計管理法規(guī)和規(guī)章。
1.2 Laws and regulations of the related state and local construction survey and design management.
1.3建設(shè)工程批準文件。1.3 Documents of Approval for Construction.
第二條 設(shè)計依據(jù)Article 2 Design Basis
2.1發(fā)包人給設(shè)計人的委托書或設(shè)計中標文件
2.1 The Trust Deed or Design Documents of the tender accepted provided to the designer by the employer;
2.2發(fā)包人提交的基礎(chǔ)資料2.2 Fundamental materials submitted by the employer;
2.3設(shè)計人采用的主要技術(shù)標準是:2.3 The major technical standards adopted by the designer are:
B-01R5-SJ-02-2010標準、規(guī)程、規(guī)范
B-01R5-SJ-02-2010 Standards, Procedures, Norms
第三條 合同文件的優(yōu)先次序Article 3 Priority of Contract Document
構(gòu)成本合同的文件可視為是能互相說明的,如果合同文件存在歧義或不一致,則根據(jù)如下優(yōu)先次序來判斷:
The documents consisting of this Contract may be deemed as demonstrating mutually; if there is any ambiguity or discordance in the contract document, the following priority shall be followed to judgment,
3.1合同書 3.1 The Contract;
3.2中標函(文件) 3.2 Letter of Acceptance (Document);
3.3發(fā)包人要求及委托書 3.3 Requirements of the employer and Letter of Authority;
3.4投標書 3.4 The Tender
第四條 本合同項目的名稱、規(guī)模、階段、投資及設(shè)計內(nèi)容(根據(jù)行業(yè)特點填寫)
Article 4 Name, Scale, Phase, Investment and design Content for the Contract Items (fill in based on industry characteristics)
10KV星摩爾購物廣場1#變電所新建工程
10KV Star Mall Plaza 1 # Substation New Construction
變電所電氣及10KV進線
Electric and 10KV inlet wire of the substation
變電所設(shè)在地下,內(nèi)設(shè)6臺1600KVA變壓器及2臺1250KVA變壓器。
The substation is underground, with six 1,600KVA transformers and two 1,250KVA transformers inside.
10KV電源分別由勸工變、歷工變電所各新出電纜新路徑電纜敷設(shè)至用戶
變電所。
The 10KV power line is laid along the new cable roads of Quangong Substation and Ligong Substation respectively, toward the customer substation with cables.
第五條 發(fā)包人向設(shè)計人提交的有關(guān)資料、文件及時間
Article 5 Relevant materials, documents and time submitted to the designer
本工程供電方案 1份 2010-2-25
Power supply scheme of this project 1 25 February, 2010
用電負荷資料 1份 2010-2-25
by the employer
Electricity load data 1 25 February, 2010
第六條 設(shè)計人向發(fā)包人交付的設(shè)計文件、份數(shù)、地點及時間
Article 6 Documents, number of copies, location and time submitted to the employer by the designer
設(shè)計圖紙 8份 2010-04-15
Design drawing 8 copies 15 April, 2010
概算書 6份 2010-04-15
Book of estimates 6 copies 15 April, 2010
注:待發(fā)包人結(jié)清全部設(shè)計費后,由設(shè)計人將設(shè)計文件交付沈陽供電公司客戶工程部
Note: After the party issuing contract settles up the total design fee, the above design documents will be submitted to the Project Division of Shenyang Power Supply Company by the designer.
第七條 費用Article 7 Expenditure
7.1雙方商定,本合同的設(shè)計費為設(shè)計費按設(shè)計價格(2002)10號文計取 萬元。收費依據(jù)和計算方法按國家和地方有關(guān)規(guī)定執(zhí)行,國家和地方?jīng)]有規(guī)定的,由雙方商定。
7.1 It is agreed between both parties that the design fee under this contract is calculated and charged according to the document No.10 (2002) Design Prices. The charging basis and method are in accordance with relevant national and local provisions, and will be determined by both parties through negotiation, if there is no relevant national or local provision.
7.2 如果上述費用為估算設(shè)計費,則雙方在初步設(shè)計審批后,按批準的初步設(shè)計概算核算設(shè)計費。工程建設(shè)期間如遇概算調(diào)整,則設(shè)計費也應做相應調(diào)整。
7.2 If the above expense is estimated design fee, both parties shall check the design fee as per the approved budgetary estimate of the preliminary design, after the examination and approval of preliminary design. During the construction of this project, if there is any adjustment in budgetary estimate, the design fee will also be adjusted correspondingly.
第八條 支付方式Article 8 Form of Payment
8.1本合同生效后三天內(nèi),發(fā)包人支付設(shè)計費總額,計 16 萬元作為定金(合同結(jié)算時,定金抵作設(shè)計費)。
8.1 The party issuing contract shall pay the total design fee, within three days after the execution of this contract, that is, 160000 RMB as a deposit (the deposit will be seen as a part of design fee, at the time of contract settlement).
8.2設(shè)計人提交 全部 設(shè)計文件之前,發(fā)包人結(jié)清設(shè)計費,不留尾款。
8.2 Before the designer submits all design documents. the design charge is all squared by the employer, and no final payment left.
8.3雙方委托銀行代付代收有關(guān)費用。
8.3 Both parties commission bank to pay and collect related fees.
第九條 雙方責任Article 9 Responsibility of Two Parties
9.1 發(fā)包人責任9.1 Responsibility of the Employer
9.1.1發(fā)包人按本合同第五條規(guī)定的內(nèi)容,在規(guī)定的時間內(nèi)向設(shè)計人提交基礎(chǔ)資料及文件,并對其完整性、正確性及時限負責。發(fā)包人不得要求設(shè)計人違反國家有關(guān)標準進行設(shè)計。
發(fā)包人提交上述資料及文件超過規(guī)定期限15天以內(nèi),設(shè)計人按本合同第六條規(guī)定的交付設(shè)計文件時間順延;發(fā)包人交付上述資料及文件超過規(guī)定期限15天以上時,設(shè)計人有權(quán)重新確定提交設(shè)計文件的時間。
9.1.1 The Employer shall deliver basic materials and documents to the designer within the specified time in accordance requirements stipulated in Article 5, and shall be responsible for their completeness, correctness and time limit. The employer shall not request the designer to design by violating the concerned national standards.
If it exceeds the prescribed time limit within fifteen (15) days when the employer delivers above materials and documents, the designer can postpone accordingly the time of delivering the design documents in accordance with Article 6 in the Contract; if it exceeds the prescribed time limit over fifteen (15) days when the employer delivers above materials and documents, the designer is entitled to decide again the time of delivery of design documents.
9.1.2發(fā)包人變更委托設(shè)計項目、規(guī)模、條件或因提交的資料錯誤,或所提交資料作較大修改,以致造成設(shè)計人設(shè)計返工時,雙方除另行協(xié)商簽訂補充協(xié)議(或另訂合同)、重新明確有關(guān)條款外,發(fā)包人應按設(shè)計人所耗工作量向設(shè)計人支付返工費。
9.1.2 When the employer alters entrusted design items, scale and conditions, or delivers the wrong materials, or delivers mostly revised materials so that the designer rework for the design, the employer shall pay for rework cost for the designer based on the amount of the work performed by the designer except the supplemental agreement (or contract ) signed separately, and the relevant articles specified again by both parties through the consultation.
Prior to signing the contract, if the employer has satisfied to design work which is done by the designer, the employer shall pay the corresponding design charge.
在未簽訂合同前發(fā)包人已同意,設(shè)計人為發(fā)包人所做的各項設(shè)計工作,發(fā)包人應支付相應設(shè)計費。
9.1.3在合同履行期間,發(fā)包人要求終止或解除合同,設(shè)計人未開始設(shè)計工作的,不退還發(fā)包人已付的定金;已開始設(shè)計工作的,發(fā)包人應根據(jù)設(shè)計人已進行的實際工作量,不足一半時,按該階段設(shè)計費的一半支付;超過一半時,按該階段設(shè)計費的全部支付。
9.1.3 During implementation of the Contract, when the employer requests to terminate and cancel the contract, the down payment paid by the employer shall not be returned if the designer doesn’t begin the design work; if the designer starts the design, the employer shall pay half of design charge in the phase if it is less than half of the actual amount of work performed by the designer; if it exceeds the half, the full design charge in the phase shall be paid in all.
9.1.4發(fā)包人必須按合同規(guī)定支付定金,收到定金作為設(shè)計人設(shè)計開工的標志。未收到定金,設(shè)計人有權(quán)推遲設(shè)計工作的開工時間,且交付文件的時間順延。
9.1.4 The employer shall pay the down payment in accordance with stipulations of the Contract. Reception of the down payment is the mark of commencement of design work for the designer. If the down payment is not received, the designer is entitled to put off the time of commencement of design work, and postpone accordingly the time of delivery of documents.
9.1.5發(fā)包人應按本合同規(guī)定的金額和日期向設(shè)計人支付設(shè)計費,每逾期支付一天,應承擔應支付金額千分之二的逾期違約金,且設(shè)計人提交設(shè)計文件的時間順延。逾期超過30天以上時,設(shè)計人有權(quán)暫停履行下階段工作,并書面通知發(fā)包人.發(fā)包人的上級或設(shè)計審批部門對設(shè)計文件不審批或本合同項目停緩建,發(fā)包人均應支付應付的設(shè)計費。
9.1.5 The Employer should pay charges for design to the Designer at the amount and date provided in this Contract. For each day of overdue payment, 2‰ of the overdue payment shall be paid as damages for overdue payment and the time for delivery by the Designer shall be extended accordingly. Where the delay of payment has exceeded 30 days, the Designer shall have the right to suspend the performance of the work at the next stage and give written notice to the Employer. In case the higher authority or competent department of design approval would not approve the design documents or the engineering construction of this contract is suspended or stopped, the Employer should pay the payable charges for design.
9.1.6發(fā)包人要求設(shè)計人比合同規(guī)定時間提前交付設(shè)計文件時,須征得設(shè)計人同意,不得嚴重背離合理設(shè)計周期,且發(fā)包人應支付趕工費。
9.1.6 The employer requests the designer should deliver the design documents ahead of the time specified by the Contract, it shall need the approval of the designer, and shall not deviate gravely from the rational design period, and the employer shall pay for the crashing charge.
9.1.7發(fā)包人應為設(shè)計人派駐現(xiàn)場的工作人員提供工作、生活及交通等方面的便利條件及必要的勞動保護裝備。
9.1.7 The Employer should offer conveniences in aspects of working, living and traffic and necessary labor-protection equipments.
9.1.8設(shè)計文件中選用的國家標準圖、部標準圖及地方標準圖由發(fā)包人負責解決。
9.1.8 The Employer shall be responsible for the national standard drawing, ministerial standard drawing and local standard drawings.
9.1.9承擔本項目外國專家來設(shè)計人辦公室工作的接待費(包括傳真、電話、復印、辦公等費用)。
9.1.9 The Employer shall bear the expenses for receiving foreign expert in charge of the engineering to the Designer's office (including expenses on fax, telephone, copy and office affairs).
9.2設(shè)計人責任9.2 Responsibilities of the Designer
9.2.1設(shè)計人應按國家規(guī)定和合同約定的技術(shù)規(guī)范、標準進行設(shè)計,按本合同第六條規(guī)定的內(nèi)容、時間及份數(shù)向發(fā)包人交付設(shè)計文件 (出現(xiàn)9.11、9.12、9.14、9.15、規(guī)定有關(guān)交付設(shè)計文件順延的情況除外).并對提交的設(shè)計文件的質(zhì)量負責。
9.2.1 The designer shall perform the design in accordance with provisions of the State and the technical codes and standards stipulated in the Contract, deliver the design documents in accordance with contents, time and number of copies to the employer specified in Article 6 (exclusion of the case where the design documents shall be prolonged accordingly stipulated in Article 9.11, 9.12, 9.14 and 9.15), and be responsible for quality of the delivered design documents.
9.2.2設(shè)計合理使用年限為 25 年。
9.2.2 The design life of the engineering construction shall be 25 years.
9.2.3負責對外商的設(shè)計資料進行審查,負責該合同項目的設(shè)計聯(lián)絡(luò)工作。
9.2.3 Responsible for examining for design materials of foreign businessman, and responsible for design liaison of the Contract project.
9.2.4設(shè)計人對設(shè)計文件出現(xiàn)的遺漏或錯誤負責修改或補充。由于設(shè)計人設(shè)計錯誤造成工程質(zhì)量事故損失,設(shè)計人除負責采取補救措施外,應免收受損失部分的設(shè)計費,并根據(jù)損失程度向發(fā)包人支付賠償金,賠償金數(shù)額由雙方商定為實際損失的 \%。
9.2.4 The designer shall be responsible for revision or supplement to the mistakes or omission of the design documents. The designer shall be free of the design charge of loss part besides remedial measures taken for casualty loss of construction quality caused by the designer due to the wrong design, and shall pay compensation money for the employer based on degree of loss. Amount of compensation which is decided by two parties through consultation is \% of actual loss.
9.2.5由于設(shè)計人原因,延誤了設(shè)計文件交付時間,每延誤一天,應減收該項目應收設(shè)計費的千分之二。
9.2.5 If the delivery of design documents is delayed for the Designer's reason, each day overdue will result in the reduction of 2‰ of the design charges for the project.
9.2.6合同生效后,設(shè)計人要求終止或解除合同,設(shè)計人應雙倍返還發(fā)包人已支付的定金。
9.2.6 After the contract enters into force, the Designer may require termination or cancellation of the contract and the Designer should return the down payment in double.
9.2.7設(shè)計人交付設(shè)計文件后,按規(guī)定參加有關(guān)上級的設(shè)計審查,并根據(jù)審查結(jié)論負責不超出原定范圍的內(nèi)容做必要調(diào)整補充。設(shè)計人按合同規(guī)定時限交付設(shè)計文件一年內(nèi)項目開始施工,負責向發(fā)包人及施工單位進行設(shè)計交底、處理有關(guān)設(shè)計問題和參加竣工驗收。在一年內(nèi)項目尚未開始施工,設(shè)計人仍負責上述工作,可按所需工作量向發(fā)包人適當收取咨詢服務費,收費額由雙方商定。
9.2.7 Upon delivery of the design documents, the Designer shall participate in the inspection on the design by the relevant higher authority as provide and shall be responsible for necessary adjustment and supplements to the content within the original scope of the design according to the inspection conclusion. The Designer shall start the construction within one year upon delivery of the design documents within the specified time limit and shall be responsible for the technological disclosure to the Employer and construction unit, handling with relevant matters on design and participation in the acceptance upon completion of the engineering construction. In case the engineering construction has not started within one year, the Designer shall still be responsible for the above work and may collect reasonable service charge for consultancy from the Employer according to the needed workload. The amount of the service charge shall be discussed and determined by the Parties.
第十條 保密Article 10 Confidentiality
雙方均應保護對方的知識產(chǎn)權(quán),未經(jīng)對方同意,任何一方均不得對對方的資料及文件擅自修改、復制或向第三人轉(zhuǎn)讓或用于本合同項目外的項目。如發(fā)生以上情況,泄密方承擔一切由此引起的后果并承擔賠償責任。
Both Parties shall protect each other’s intellectual property rights. Without prior consent, neither party shall revise, copy or transfer to a third party or use for the project other than the project of this Contract any materials and documents of the other party. Under such circumstances, the disclosing party shall be responsible for all the any consequence it resulted and shall bear the relevant compensation.
第十一條 仲裁Article 11: Arbitration
本建設(shè)工程設(shè)計合同發(fā)生爭議,發(fā)包人與設(shè)計人應及時協(xié)商解決。也可由當?shù)亟ㄔO(shè)行政主管部門調(diào)解,調(diào)解不成時,雙方當事人同意由 沈陽 仲裁委員會仲裁。雙方當事人未在合同中約定仲裁機構(gòu),當事人又未達成仲裁書面協(xié)議的,可向人民法院起訴。
If any dispute arises in connection with this Engineering Service Contract, it shall be settled by friendly consultation of the Parties, or be submitted to the competent local construction administration department for mediation. Where the dispute can not be settled by mediation, it shall be submitted to the Shenyang Arbitration Committee for settlement. Where the Parties have not agreed on the arbitration organization in the Contract nor conclude arbitration agreement in written form, the dispute will be brought to the People’s Court.
第十二條 合同生效及其他Article 12: Contract effective and miscellaneous
12.1發(fā)包人要求設(shè)計人派專人長期駐施工現(xiàn)場進行配合與解決有關(guān)問題時,雙方應另行簽訂技術(shù)咨詢服務合同。
12.1 As per the request of the Employer for dispatch of personnel to stay on the Construction site so as to coordinate and solve relevant issues, the individual technical consultant service contract shall be signed by both parties.
12.2設(shè)計人為本合同項目的服務至施工安裝結(jié)束為止。
12.2 Service provided by the Designer for the Project in this Contract will be concluded until the completion of construction and installation.
12.3本工程項目中,設(shè)計人不得指定建筑材料、設(shè)備的生產(chǎn)廠或供貨商。發(fā)包人需要設(shè)計人配合建筑材料、設(shè)備的加工訂貨時,所需費用由發(fā)包人承擔。
12.3 In the projects of the Contract, Designer shall not appoint manufacturers or Designers of construction materials and equipments. Where there is a necessity that Designer shall cooperate with Employer in ordering the process of construction materials and equipments, the relevant charge shall be paid by Employer.
12.4發(fā)包人委托設(shè)計人配合引進項目的設(shè)計任務,從詢價、對外談判、國內(nèi)外技術(shù)考察直至建成投產(chǎn)的各個階段,應吸收承擔有關(guān)設(shè)計任務的設(shè)計人員參加。出國費用,除制裝費外,其他費用由發(fā)包人支付。
12.4 The Employer entrusted the Designer to cooperate with the engineering work of imported project and design personnel undertaking relevant design assignment shall be included in all stages from enquiry, business negotiation, domestic and overseas technical inspection until the production period. The charge for overseas business trip and other relevant charge will be paid by Employer except the charge for purchasing dress.
12.5發(fā)包人委托設(shè)計人承擔本合同內(nèi)容以外的工作服務,另行簽訂協(xié)議并支付費用。
12.5 Additional agreement for any other service, which Employer entrusts Designer to provide, however, out of the scope of the Contract, shall be signed and the payment shall be paid correspondingly.
12.6由于不可抗力因素致使合同無法履行時,雙方應及時協(xié)商解決。
12.6 For any failure to perform any term or condition of this Contract due to the force majeure, both parties shall, in good faith, attempt to settle amicably and by mutual agreement.
12.7本合同雙方簽字蓋章即生效。一式 貳 份,發(fā)包人 壹 份,設(shè)計人 壹 份。
12.7 The Contract is effective once after both parties stamped and signed. There are totally __two_ copies of the Contract, Employer retains __one_ copies, and Designer retains __one__ copies.
12.8本合同生效后,按規(guī)定應到項目所在地省級建設(shè)行政主管部門規(guī)定的審查部門備案;雙方認為必要時,到工商行政管理部門鑒證。雙方履行完合同規(guī)定的義務后,本合同即行終止。
12.8 Once this Contract became effective, it should be registered in the Auditing Section stipulated by Provincial Administrative Ministry of Construction where the Project locates. Where is necessity mutually agreed by both parties, the Contract shall be certified by Local Administration for Industry and Commerce. This Contract is to be concluded once after both parties fulfilled their own responsibilities.
12.9雙方認可的來往傳真、電報、會議紀要等,均為合同的組成部分,與本合同具有同等法律效力。
12.9 Any correspondence, include faxes, telegram, meeting minutes agreed by both parties, are components of the Contract, which shall have the same validity with this Contract.
12.10未盡事宜,經(jīng)雙方協(xié)商一致,簽訂補充協(xié)議,補充協(xié)議與本合同具有同等效力。
12.10 As for matters not covered in this Agreement, supplementary agreement may be concluded by the Parties separately and such supplementary agreement shall have the same legal validity with this Contract.
發(fā)包人名稱:Name of the Employer: 設(shè)計人名稱:Name of the Designer:
(蓋章)(Stamp) (蓋章)(Stamp)
法定代表人:(簽字)Legal representative: (signature) 法定代表人:(簽字)Legal representative: (signature)
委托代理人:(簽字)Authorized proxy: (signature) 委托代理人:(簽字)Authorized proxy: (signature)
項目經(jīng)理:(簽字)Project Manager: (signature) 項目經(jīng)理:(簽字) Project Manager: (signature)
住 所: Address: 住 所:Address:
郵政編碼: Postcode: 郵政編碼: Postcode:
電 話: Tel.: 電 話:Tel.:
傳 真: Fax: 傳 真:Fax:
開戶銀行: Bank: 開戶銀行: Bank:
銀行帳號: Bank account: 銀行帳號:Bank account:
建設(shè)行政主管部門備案: 鑒證意見: Verification opinion:
Record at the competent construction
administration department:
(蓋章) (Stamp) (蓋章)(Stamp)
備 案 號: 經(jīng) 辦 人:
Record No.: Agent:
備案日期: 年 月 日 鑒證日期: 年 月 日
看了“化工建設(shè)工程設(shè)計合同范本”的人還看了: